SUMMARY OF SERVICES
The Co-Developer and MDOs/FBOs shall co-manage a full-service Development Team to refine and implement the Site Concept Plan and direct the Project's design, development, and financing. The Co-Developer, subject to the financing and implementation plan, shall propose and incorporate a variety of funding sources, including Low-Income Housing Tax Credits (LIHTC), Bond Financing, Federal Home Loan Bank, Permanent Debt, CDBG, CDBG-DR, FEMA, HOME Investment Partner(s)ships (HOME), Private Foundation Funds and such other sources as may be available and appropriate. The Co-Developer is expected to be experienced with the requirements of all financing programs proposed for use. MDOs/FBOs will undertake no financial or guaranty obligations unless explicitly accepted in writing by MDOs/FBOs.
The selected Co-Developer will implement the development program pursuant to the Master Development Agreement (MDA) between the Co-Developer and the MDO/FBO.
MDOs/FBOs also reserve the right to select one or more Co-Developers. The Co-Developers will work solely with MDOs/FBOs to develop the Project.
MDOs/FBOs will be co-owners and must be included in and approve critical decisions in all aspects of the Project's planning and development, including, but not limited to, preparing documents, discussions with potential and selected investors, meetings with contractors, consultants, and stakeholders, and selecting key team members. Any reference in this RFQ to MDOs/FBOs having rights of review, approval, etc., shall mean MDOs/FBOs or their affiliates.
Predevelopment
MDOs/FBOs will be involved in the predevelopment process and review and must approve all project contracts, invoices, and draws for approval. Such approval shall not be unreasonably withheld.
- Investor Solicitation - MDOs/FBOs will review the Co-Developer's construction financing and equity investor solicitation, list of potential investors, and responses. The Co-Developer shall conduct the investor solicitation process in a way that ensures maximum participation. Such approval shall not be unreasonably withheld.
- Participation in Site/Unit Design - MDOs/FBOs expect the Co-Developer to review and incorporate the completed site conceptual design into the design documents. MDOs/FBOs will be involved throughout the design processes to finalize the site plan, the building designs, and the floor plans. MDOs/FBOs will also review and approve the construction drawings and specifications. Such approval shall not be unreasonably withheld.
- Preferred Property Management Concept - MDOs/FBOs expect to participate in selecting the residential property manager. Such approval shall not be unreasonably withheld.
- Marketing and Lease-up - The property manager(s), selected by the Co-Developer with the approval of the MDO/FBO, shall create and implement a marketing and lease-up strategy for the rental units and, if applicable, commercial or retail space to ensure that stabilized occupancy is achieved in compliance with all applicable financing and land-use agreements.
Financing
- Predevelopment Funding - MDOs/FBOs expect the Co-Developer to provide one hundred (100%) percent of the pre-approved third-party predevelopment costs.
- Development Fees - MDOs/FBOs or their affiliates will act as co-developers and receive a negotiated share of the Developer Fee.
- Asset Manager - MDOs/FBOs will have asset management responsibilities related to units in which they or their affiliates have an ownership interest.
MINIMUM REQUIREMENTS FOR CO-DEVELOPER
Respondents to the RFQ must meet the following minimum requirements:- Must have at least five (5) years of experience developing affordable housing of comparable size and scope to the Projects outlined in this RFQ, including knowledge of and experience with 9% (LIHTC) Low-Income Housing Tax Credits.
- Must have developed and completed at least two projects of comparable size and scope to the Projects outlined in this RFQ within the last ten (10) years.
- Must have experience successfully accessing private equity, debt financing, government grants, and/or loans and/or be able to do so reasonably.
ROLE OF CO-DEVELOPER
MDOs/FBOs will be co-owners and must be included in and approve critical decisions in all aspects of the Project's planning and development, including, but not limited to, preparing documents, discussions with potential and selected investors, meetings with contractors, consultants, and stakeholders, and selecting key team members. Any reference in this RFQ to MDOs/FBOs having rights of review, approval, etc., shall mean MDOs/FBOs or their affiliates.
Throughout the development effort, including each component phase, the Co-Developer will work closely with all stakeholders, including MDO/FBO and its consultants, the surrounding community, the municipalities, and appropriate federal/local agencies. In addition, the Co-Developer will ensure that the development plan is approved, financed, and implemented promptly.
General
Assist MDOs/FBOs with refining their Site Concepts to achieve the desired objectives for the Projects
Implement Development Efforts – Provide the necessary expertise, supervision, and guarantees to implement all aspects of the development fully and expeditiously as required by the Master Development Agreement (MDA). The MDA is a contract between MDO/FBO or an affiliate thereof and the Co-Developer that details the obligations of both parties and specifies the standards and conditions that will govern the development of the Site.
Acquisition Financing –Co-Developer will obtain all financing necessary to satisfy all site acquisition requirements in a manner mutually agreeable and acceptable to all lenders, investors, and parties in interest.
Hire and Manage Additional Consultants and Development Team Members Necessary for Planning and Implementation – The Development Team shall include, at a minimum, the Co-Developers, Project Architect, Attorney, Energy Consultant, and Property Manager. Proposed Development Team members must be submitted with the Offeror’s response to this RFQ.
Partner with MDOs/FBOs to Develop Funding Applications as Necessary to Fully Implement the Development Strategy - Procure other consultants or contractors and coordinate all tasks required for all financing applications, finalizing the site-specific development plans and all implementation tasks. At a minimum, the Co-Developer will jointly procure, oversee, and manage consultants appropriately as necessary to complete funding applications, master planning, architectural, environmental review, market analysis, geotechnical studies, civil, mechanical, and electrical engineering, and any other activities deemed necessary by the Co-Developer and MDOs/FBOs. Respondents are strongly encouraged to demonstrate participation on their team, whether by joint-venture arrangements or otherwise, of local expertise in areas relevant to the planning and development process, including LIHTC financing, design, and construction matters.
Maintain Communication Regarding Project Progress with MDOs/FBOs, Lenders, Investor, All Key Stakeholders, and the Larger Public – MDOs/FBOs will establish a regular schedule of team meetings in which the Co-Developer will participate. Moreover, the Co-Developer will be responsible for submitting monthly progress reports to MDOs/FBOs in such formats and media as it might direct on the project status and schedule, including but not limited to design, permits, financing, resident coordination, etc.
Develop and Maintain Quality Control Measures—The Co-Developer is responsible for ensuring the Project is constructed and managed with the highest-quality materials and workmanship. In addition, the Co-Developer will be required to implement quality assurance and control measures to ensure adequate performance by all parties in all aspects of the program.
Develop and Maintain a Detailed Development Schedule and Critical Path Schedule - The Co-Developer will develop and maintain a detailed schedule of events predicated on financing deadlines that include predevelopment activities, construction start, project stabilization, and permanent loan close. In addition, they will develop a Critical Path Schedule for all phases of construction, lease-up, and stabilization.
Be Responsive to the Local Community, Neighborhood, and Governmental Interest – The Co-Developer will work with MDOs/FBOs to promote and maintain good relations with community and neighborhood groups and federal, state, and local governments.
Compliance with Laws and Regulations – The Co-Developer will comply with all applicable federal and local laws, rules, and regulations for the activities required by the Master Development Agreement.
MBE/WBE/BIPOC Opportunities – The Co-Developer will take all necessary affirmative steps to assure that disadvantaged, minority, women-owned business, and BIPOC-led enterprises (MBE/WBE/BIPOC) are used to the greatest extent feasible in compliance with federal policy and consistent with LISC NY and MDOs/FBO's Employment, Training, and Contracting Policy. MDO/FBO’s goals and expectations are that the Co-Developer will meet or exceed 30% of the total value of all contracts and subcontracts awarded to MBE/WBE/BIPOC-led firms.
Local Contracting —The Co-Developer shall undertake reasonable efforts to involve qualified local consultants and contractors in the redevelopment effort. For this purpose, "local" means firms located in the locality in which the Project is being developed. It is important to note that any proposed architect of record and engineers must be licensed to work in the State of New York and included in the Respondent's Statement of Qualifications in response to this RFQ.
Predevelopment
Planning and Design - The selected Co-Developer and MDOs/FBOs shall work jointly to lead a progressive architectural team rendering a signature state-of-the-art design in affordable housing utilizing the Principles for Building Resilience in housing in New York State.
Prepare Development Plan - In consultation with MDOs/FBOs, the residents, the community, leaders, and other interested stakeholders, the Co-Developer will refine the concept plan for the Project to be consistent with program goals and acceptable to MDOs/FBOs.
Plans and Specifications - Subject to the review and approval of MDOs/FBOs, the Co-Developer, jointly with MDOs/FBOs, will be responsible for refining and finalizing the infrastructure and building plans and specifications prepared to date by MDOs/FBOs to ensure they comply with the requirements of all permitting and regulatory entities. All such documents and designs will be subject to MDOs/FBOs' review and approval.
Financing
Produce an Overall Financing Plan - The Co-Developer, in conjunction with MDOs/FBOs, will finalize the financing plan for the overall development effort. The comprehensive financing plan and market analysis will be developed alongside the development plan. The development plan shall reflect the realities of the overall financing plan, market analysis, and programmatic goals of MDOs/FBOs.
Financing Applications (s) - Per the Master Development Agreement, the Co-Developer will be required to pursue diligently and use best efforts to obtain all financing necessary to implement the development plans in a timely fashion, which may include, but not be limited to - tax credits, tax-exempt bonds, federal/state/local funds, and private debt.
Maximize the Leveraging of Public and Private Resources - MDO/FBO and Co-Developer shall maximize and leverage public and private resources to pursue all reasonable financing and funding sources from wherever situated. The parties shall jointly coordinate, discuss, and negotiate all financing terms with financial institutions and private partners, etc. Said negotiations shall be subject to review and approval by MDO/FBO. Any identity of interest between the Co-Developer and any lender, syndicator, or other financing Partner(s) must be timely disclosed, and the Co-Developer must demonstrate how the proposed terms are most favorable to other terms available in the market.
Obtain Equity Investment - Utilizing an open and competitive process, MDO/FBO and the Co-Developer shall obtain equity financing commitments with the best terms currently available per the Master Development Agreement. MDO/FBO intends to participate in developing the solicitation documents for investors by reviewing the letters of interest received and ranking and scoring all responses. All investors for the Project will require the approval of MDO/FBO and the co-developer.
Guarantees - In accordance with the Master Development Agreement, provide all guarantees required for the successful financing of the development effort, including completion guarantees, operating deficit guarantees, tax credit adjuster or recapture guarantees, and guarantees of performance under the Agreement. In addition, MDO/FBO will require that the Co-Developer demonstrate financial ability to honor the guarantees.
Operating Feasibility – As required in the Master Development Agreement, structure such reserves and other devices as necessary to guarantee the long-term operating feasibility of the Project reasonably.
Accounting/Financing - Pursuant to the Master Development Agreement, MDO/FBO and the Co-Developer shall maintain all accounting and finance records, and the Co-Developer shall ensure Project financing is available at the appropriate times and utilized in the appropriate manner.
Construction
Hire a Qualified General Contractor or Construction Manager to Oversee Construction Activities – MDO/FBO and Co-Developer will create and implement a competitive process for selecting the most qualified General Contractor or Construction Manager. During construction, the Co-Developer shall provide oversight and management of construction activities to ensure the expeditious implementation of the Project, subject to the review and approval of MDO/FBO. As regular on-site construction monitoring is critical to the success of the Project, the Co-Developer must have a reasonable on-site presence during the term of construction. Any identity of interest between the Co-Developer and the General Contractor or Construction Manager must be disclosed and approved by MDO/FBO, lenders, and investors.
Facilitate Necessary Site Improvements – According to the Master Development Agreement, the Co-Developer, in cooperation with MDO/FBO, shall initiate and complete site work and infrastructure construction with review and approval by MDO/FBO.
Implement Development Program – Per the final development plans approved by lenders, investors, and regulatory agencies and subject to review and approval of MDO/FBO, the Co-Developer will develop all improvements associated with the development program.
Ownership and Asset Management
Organize Ownership Entity - Upon completion of the development plan, the MDO/FBO and the Co-Developer will jointly structure and organize an ownership entity approved by MDO/FBO and meeting the requirements of any and all other financing entities. Said entity shall be subject to approval by lenders, investors, et al.
Ensure the Short- and Long-term Viability of the Project - MDO/FBO and Co-Developer shall jointly develop and implement marketing, re-occupancy, asset, and property management plans to ensure the Project’s short- and long-term viability.