SITE CONCEPT PLANS
As stated above, the property, located at Block 1229, Lot 90,
spans 12,000 square feet and falls under the R5B zoning. The zoning floor area
(ZFA) is specified at 21,000 square feet.
The preferred concept plan, labeled Option A, outlines a proposal
for 24 affordable housing units (refer to Attachment B). This plan utilizes
AIRS to boost density and necessitates a waiver from CPC for height. On the
other hand, the alternative concept plan, Option B, calls for 25 affordable
housing units without the need for a height waiver (refer to Attachment B).
Concept A is favored due to its ability to accommodate two additional
two-bedroom units, enabling the client to assist larger families.
Both concepts entail the demolition of two existing structures. At
present, one of the buildings is leased by a 501(c)(3) for immigration services
and will need to be relocated, while the second structure is currently vacant.
Up to this point, the LISC NY team and EDLI have completed the
concept plan. As previously mentioned, EDLI has assembled a team of
consultants, including a tax accountant and a land use attorney. This project
will require a City Planning Commission (CPC) waiver for height (24-57).
As stated above, Attachment B illustrates
the concept plan for the Project along with the proposed floor plans.
UNIT
MIX
|
Bedroom Size
|
Option
A
|
Option
B
|
Studio
|
12 (50%)
|
12 (48%)
|
1 Bedroom
|
5 (21%)
|
8 (32%)
|
2 Bedroom
|
7 (29%)
|
5 (20%)
|
Total
|
24
|
25
|
Design Principles
- Include replacement unit requirements and preferred concept plans in the proposal
- Explore a multi-faceted approach to create a vibrant mixed-income and mixed-use neighborhood that is the highest and best use of the land
- Integrate environmental sustainability “green” construction and design practices, optimal energy efficiency through the incorporation of on-site renewable energy, and adherence to LEED or green community certification standards
- Establish an accessible, pedestrian-oriented environment that can serve as a model of adequate accessibility through quality streetscape, open space, and design
- Promote community interconnectivity between residents, neighborhood, and the community
- Foster meaningful engagement of residents and other stakeholders throughout the implementation period
- Feature high-quality, context-sensitive architectural design that is respectful to the surrounding neighborhood
- Develop a creative and viable financial plan that does not require EDLI funding
- Coordinate with other local and community-driven development plans
SUMMARY OF SERVICES
The
Co-Developer shall, subject to consultation with and the reasonable approval of
EDLI, manage a full-service Development Team to refine and implement the Site
Concept Plan and direct design, development, and financing of the Project. The
Co-Developer, subject to the consultation and reasonable approval of EDLI, will
be responsible for developing a feasible financing and implementation plan that
incorporates a variety of funding sources such as Low-Income Housing Tax
Credits (LIHTC), Bond Financing, Federal Home Loan Bank, Permanent Debt, CDBG,
CDBG-DR, FEMA, HOME Investment Partner(s)ships (HOME), Private Foundation Funds
and such other sources as may be available and appropriate. The Co-Developer is
expected to be experienced with the requirements of all financing programs it
proposes to use. EDLI will undertake no financial or guaranty obligations
unless explicitly accepted in writing by EDLI.
The
selected Co-Developer will implement the development program per EDLI-approved
schedule. EDLI's goal is to commence construction in an initial phase in the
first quarter of 2024.
EDLI
also reserves the right to select one or more Co-Developers. The Co-Developer
will be solely responsible for working with EDLI to redevelop the Project.
ROLE OF EDLI
EDLI,
though an affiliate will be a co-owner (preferably with a majority interest)
and must be included in and have the approval of key decisions in all aspects
of planning and development of the Project, including but not limited to
preparing documents, discussions with potential and selected investors,
meetings with contractors, consultants and stakeholders and selecting key team
members. Any
reference in this RFP to EDLI having rights of review, approval, etc. that
reference to EDLI in those contexts shall mean EDLI and/or EDLI's affiliate.
Predevelopment
As noted above, EDLI has completed a significant part of the required pre-development activities and will be involved in refining and completion of the predevelopment process, including review and must approve all project contracts, invoices, and draws for approval.
Investor Solicitation – EDLI will review the Co-Developer construction financing and equity investor solicitation, the list of potential investors, and the responses. The Co-Developer shall conduct the investor solicitation process in a form that ensures maximum participation.
Participation in Site/Unit Designs – EDLI expects the Co-Developer to review the conceptual design completed for the Site and use it as the basis for preparing further design documents. Note that EDLI has completed 90 percent of the construction drawing for the mixed-use building. EDLI will be involved throughout the design process and will work with the Co-Developer to finalize the design and construction documents. Also, EDLI will review and approve the construction drawings and specifications.
Property Management – EDLI, in conjunction with the Co-Developer shall select the property manager, subject to the reasonable review and approval of the Co-Developer, lender, and investor.
Marketing and Lease-up - The property manager, selected by EDLI and approved by the Co-Developer, shall create, and implement a marketing and lease-up strategy for the rental units and, if applicable, commercial, or retail space, to ensure that stabilized occupancy is achieved in compliance with all applicable financing and land-use agreements.
Financing
Predevelopment Funding – EDLI expects the Co-Developer to provide one hundred (100) percent of the pre-approved third-party predevelopment costs.
Development Fees – EDLI or its affiliate will act as co-developer and expects a minimum thirty (30) percent share of the Developer Fee (paid and deferred), but a more significant amount of development fee is preferred.
Acquisition Financing – EDLI owns the project site. Per State law, EDLI must receive fair and reasonable compensation to transfer the property to the ownership entity. EDLI expects the Co-Developer to obtain the financing necessary to compensate the Church for the transfer of the property. EDLI also expects the Co-Developer to assist with structuring the acquisition of the Site through a sale or ground lease, whichever is mutually agreeable to EDLI and the Co-Developer and acceptable to lenders and investors.
Insurance Requirements – The Co–Developer shall comply with the insurance requirements outlined in Attachment C of this RFP and the insurance requirements of lenders and investors.
Asset Manager – EDLI will have asset management responsibilities related to units in which EDLI or its affiliate has an ownership interest. EDLI will monitor and enforce the terms of its lease and the Regulatory and Operating Agreement with the Co-Developer and require that all housing units be managed following applicable local, state, and federal requirements.
Contract Administration
EDLI will attend all construction meetings and reviews. Approve all construction drawings, amendments, and monitor the construction process from bidding to contract closeout.
MINIMUM REQUIREMENT FOR CO-DEVELOPER
Respondents to the RFP must meet the following minimum requirements:
- Must have at least five years of experience developing affordable housing of comparable size and scope to the Project outlined in this RFP
- Must have developed and completed within the last ten years at least two projects of comparable size and scope to the Project outlined in this RFP
- Must have experience successfully accessing private equity, debt financing, and government grants or loans
ROLE OF CO-DEVELOPER
Throughout the development effort, including each component phase, the Co-Developer will work closely with all stakeholders, including EDLI, EDLI staff, EDLI consultants, the surrounding community, the municipalities, and appropriate federal/local agencies. In addition, the Co-Developer will ensure that the development plan is approved, financed, and implemented promptly.
General
Assist EDLI with refining its Site Concept to achieve its project objectives for the Project.
Oversee and Implement Development Efforts – Provide the necessary staffing, expertise, supervision, and guarantees to implement all aspects of the Development fully and expeditiously as required by the Master Development Agreement (MDA). The MDA is a contract between EDLI or an affiliate thereof and the Co-Developer that details the obligations of both parties and specifies the standards and conditions that will govern the development of the Site.
In Cooperation with EDLI, Hire and Manage Consultants and Development Team Members Necessary for Planning and Implementation – Note the EDLI has engaged the services of an architect, site and civil engineer, financial consultant, and contractor. Development Team members must be submitted with the Offeror’s response to this RFP.
Develop funding applications as necessary to fully implement the development strategy. Procure other consultants or contractors and coordinate all tasks required for all financing applications, finalizing the site-specific development plans and all implementation tasks. At a minimum, the Co-Developer will need to procure, oversee, and manage all consultants appropriately as necessary to complete funding applications, master planning, architectural, environmental review, market analysis, geotechnical studies, civil, mechanical, and electrical engineering, and any other activities deemed necessary by the Co-Developer and EDLI. Respondents are strongly encouraged to demonstrate participation on their team, whether by joint-venture arrangements or otherwise, of local expertise in areas of relevance to the planning and development process, including LIHTC financing, design, and construction matters.
Maintain Communication Regarding Project Progress with EDLI, lenders, investors, all key stakeholders, and the larger public – EDLI will establish a regular schedule of team meetings in which the Co-Developer will participate. Moreover, the Co-Developer will be responsible for submitting monthly progress reports to EDLI in such formats and media as it might direct, on the project status and schedule, including but not limited to design, permits, financing, resident coordination, etc.
Develop and Maintain Quality Control Measures – The Co-Developer is responsible for ensuring the Project is constructed and managed with the highest quality materials and workmanship. In addition, the Co-Developer will be required to implement quality assurance and control measures to ensure adequate performance by all parties in all aspects of the program.
Develop and Maintain a Detailed Development Schedule and Critical Path Schedule – The Co-Developer will develop and maintain a detailed schedule of events predicated on financing deadlines that include predevelopment activities, construction start, project stabilization, and permanent loan close. In addition, develop a Critical Path Schedule for all phases of construction, and lease-up and stabilization.
Be Responsive to Local Community, Neighborhood, and Governmental Interests – The Co-Developer will work with EDLI to promote and maintain good relations with community and neighborhood groups, federal, state, and local governments.
Compliance with Laws and Regulations – The Co-Developer will comply with all applicable federal and local laws, rules, and regulations applying to the activities required by the Master Development Agreement.
MBE/WBE/BIPOC Opportunities – The Co-Developer will take all necessary affirmative steps to assure that disadvantaged, minority, women-owned business, and BIPOC-led enterprises (MBE/WBE/BIPOC) are used to the greatest extent feasible in compliance with federal policy and consistent with LISC NY and MOMB’Cs Employment, Training and Contracting Policy. EDLI’s goals and expectations are that the Co-Developer will meet or exceed 30% of the total value of all contracts and subcontracts awarded to MBE/WBE/BIPOC-led firms.
Local Contracting – The Co-Developer shall undertake reasonable efforts to involve qualified local consultants and contractors in the development effort. For this purpose, “local” means firms in Lackawanna, New York. It is important to note that the architect of record and engineers must be licensed to work in the State of New York and must be included in the Respondent’s Statement of Qualifications in response to this RFP.
Predevelopment
Prepare Feasibility Assessments, Market Analyses, and Appraisals – To finalize the overall development approach for each Site, prepare such feasibility assessments, market analyses, and appraisals as necessary to confirm the respective development approach. The Co-Developer will also be responsible for additional market analyses and appraisals to develop and obtain financing for each development phase.
Planning and Design – As stated above, EDLI has engaged a design team. EDLI will work with the Co-Developer to develop a signature design in affordable housing utilizing the Principles for Building Resilience in state-of-the-art housing in the State of New York.
Grant Writing and Related Funding Assistance – The Co-Developer shall fully apply for all grant opportunities possible. The Co-Developer will also be required to submit other funding applications to help finance the projects.
Prepare Development Plans – In consultation with EDLI, the residents, the community, and other interested stakeholders, the Co-Developer will refine the plan for development consistent with program goals and as acceptable to the EDLI.
Obtain Environmental Clearances – In collaboration with EDLI, the Co-Developer will procure the necessary consultants and prepare the documents to obtain environmental clearances from all interested agencies.
Plans and Specifications – Subject to the review and approval of EDLI, the Co-Developer will work with EDLI to complete the design and specifications that will comply with the requirements of all permitting and regulatory entities. All documents and designs will be subject to EDLI's review and approval.
Financing
Produce an Overall Financing Plan – Subject to EDLI's review and approval, the Co-Developer will produce a viable financing plan for the overall development effort. The comprehensive financing plan will be developed alongside the development plan and market analysis. The development plan shall reflect the realities of the overall financing plan and market analysis while the financing plan will reflect the goals of EDLI.
Financing Application(s) – Per the Master Development Agreement, the Co-Developer will be required to pursue diligently and use best efforts to obtain all financing necessary to implement the development plans in a timely fashion, which may include, but not be limited to - tax credits, tax-exempt bonds, federal/state/local funds, and private debt.
Maximize the Leveraging of Public and Private Resources – The Co-Developer shall maximize the leveraging of public and private resources by pursuing all reasonable sources of financing and utilizing various Partner(s)s and Partnerships. In addition, the Co-Developer shall take full responsibility for securing all financing sources promptly. Coordinate discussion and negotiations with financial institutions and private Partners (s)s. All financing terms are subject to review and approval by EDLI. In the case of any identity of interest between the Co-Developer and any lender, syndicator, or other financing Partner(s), the Co-Developer must demonstrate how the proposed terms are most favorable to other terms available in the market.
Obtain Equity Investment – Using an open and competitive process, obtain equity financing commitment on the best terms currently available as required by the Master Development Agreement and subject to EDLI’s approval. EDLI intends to participate in developing the solicitation documents for investors by reviewing the letters of interest received and the ranking and scoring of all responses. In addition, EDLI will need to approve the investors for each Project.
Guarantees – In accordance with the Master Development Agreement, provide all guarantees required for the successful financing of the development effort, including completion guarantees, operating deficit guarantees, and tax credit adjuster or recapture guarantees and guarantees of performance under the Agreement. In addition, EDLI will require that the Co-Developer demonstrate financial ability to honor the guarantees and indicate how they intend to honor the guarantees if necessary.
Operating Feasibility – As required in the Master Development Agreement, structure such reserves and other devices as necessary to guarantee the long-term operating feasibility of the Project.
Accounting/Financing – As to be provided for in the Master Development Agreement, maintain accounting records and ensure Project financing is available at the appropriate times and utilized in the appropriate manner.
Construction
Facilitate Necessary Site Improvements – According to the Master Development Agreement, the Co-Developer shall work with EDLI to complete site work and infrastructure construction with review and approval by EDLI.
Implement Development Program – Per the final development plans approved by lenders, investors, and regulatory agencies and subject to review and approval of EDLI, the Co-Developer will develop all improvements associated with the development program.
Ownership and Asset Management
Organize Ownership Entity – Upon completion of the development plan and its acceptance by EDLI, the selected Co-Developer will be expected to organize an ownership entity and structure approved by EDLI and the requirements of other financing entities.
Ensure the Short- and Long-Term Viability of the Redeveloped Projects – The Co-Developer shall develop and implement marketing, re-occupancy, asset, and property management plans to ensure each Project's short- and long-term viability.